General Contractor Contract

General Contractor Contract Template for Canada

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your General Contractor Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a General Contractor Contract for a large-scale commercial warehouse construction project in Ontario, with specific provisions for phased completion milestones starting March 2025 and incorporating sustainable building requirements."

Document background

The General Contractor Contract serves as a fundamental legal instrument in Canadian construction projects, establishing the rights, obligations, and responsibilities between property owners and general contractors. This document is essential when engaging a general contractor for any significant construction work, whether commercial, residential, or industrial. It incorporates crucial elements required by Canadian federal and provincial legislation, including compliance with the Construction Act, Occupational Health and Safety regulations, and provincial building codes. The contract addresses key aspects such as payment terms, construction timelines, quality standards, insurance requirements, and dispute resolution mechanisms, while allowing for customization based on project-specific needs and provincial variations in construction law. It's designed to protect both parties' interests while ensuring smooth project execution within the Canadian legal framework.

Suggested Sections

1. Parties: Identification and details of the Owner and the General Contractor, including legal names, addresses, and registration numbers

2. Background: Context of the agreement, including project overview and parties' intentions

3. Definitions: Detailed definitions of key terms used throughout the contract

4. Scope of Work: Detailed description of the construction work to be performed, including specifications and deliverables

5. Contract Price and Payment Terms: Total contract value, payment schedule, progress payments, and holdback requirements

6. Project Timeline: Start date, completion date, milestones, and provisions for extensions

7. Contractor's Obligations: Key responsibilities including permits, licenses, workforce, materials, and supervision

8. Owner's Obligations: Responsibilities of the owner including site access, approvals, and owner-supplied materials

9. Changes and Change Orders: Process for requesting, approving, and implementing changes to the scope of work

10. Insurance and Indemnification: Required insurance coverage and indemnification obligations of both parties

11. Health and Safety: Safety requirements, compliance with regulations, and safety reporting procedures

12. Warranties and Deficiencies: Warranty terms, deficiency correction process, and quality standards

13. Termination: Conditions and procedures for contract termination by either party

14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

15. General Provisions: Standard legal provisions including governing law, notices, and assignment rights

Optional Sections

1. Environmental Protection: Specific environmental requirements and procedures, used when project has significant environmental implications

2. Subcontractor Management: Rules and procedures for engaging and managing subcontractors, used when subcontracting is permitted

3. Force Majeure: Provisions for handling unforeseen circumstances and events beyond parties' control

4. Liquidated Damages: Specific damages for delay or non-performance, used when parties agree to predetermined damage amounts

5. Bonding Requirements: Performance and payment bond requirements, used for larger projects or when required by owner

6. Site Security: Special security requirements, used for sensitive or high-security locations

7. Quality Control Program: Detailed quality control procedures, used for complex projects with specific quality requirements

8. Material Storage and Handling: Specific requirements for material management, used when project involves sensitive or valuable materials

Suggested Schedules

1. Schedule A - Scope of Work Details: Detailed specifications, drawings, and technical requirements

2. Schedule B - Price Breakdown: Detailed cost breakdown including labor, materials, and overhead

3. Schedule C - Project Schedule: Detailed timeline with milestones and critical path activities

4. Schedule D - Required Insurance: Specific insurance requirements and coverage limits

5. Schedule E - Key Personnel: List of key project personnel and their responsibilities

6. Schedule F - Equipment and Materials: List of major equipment and materials to be used

7. Schedule G - Safety Procedures: Detailed safety protocols and procedures

8. Schedule H - Forms and Certificates: Required forms including payment applications and completion certificates

9. Appendix 1 - Technical Specifications: Detailed technical specifications and requirements

10. Appendix 2 - Site Plan: Detailed site plans and layouts

Authors

Alex Denne

Head of Growth (Open Source Law) @ tiktok��˰� | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Commercial Construction

Residential Construction

Industrial Construction

Infrastructure Development

Real Estate Development

Institutional Construction

Healthcare Facilities

Educational Facilities

Retail Construction

Manufacturing Facilities

Hospitality Construction

Government Buildings

Transportation Infrastructure

Relevant Teams

Legal

Construction

Project Management

Procurement

Finance

Operations

Risk Management

Quality Assurance

Health and Safety

Commercial

Development

Contracts Administration

Relevant Roles

Construction Project Manager

Contract Administrator

Legal Counsel

Property Developer

Facility Manager

Construction Manager

Risk Manager

Procurement Manager

Chief Financial Officer

Operations Director

Site Superintendent

Quality Control Manager

Health and Safety Coordinator

Cost Controller

Project Engineer

Commercial Director

Development Manager

Find the exact document you need

Joint Venture Agreement Building (Construction)

Canadian-law governed agreement establishing a joint venture between multiple parties for construction project collaboration, including structure, responsibilities, and risk allocation.

tiktok���˰�

How a Sales & Marketing Lead uses tiktok���˰� to reduce contract drafting time by 95%

Let's create your General Contractor Contract

Authors

Alex Denne

Find the exact document you need

Joint Venture Agreement Building (Construction)

Owner Builder Contractor Agreement

Agreement For Building Contractor

Contractor To Subcontractor Contract

Builder Client Contract

Land Owner Builder Agreement

Contract For House (Construction)

Third Party Agreement (Construction)

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Contract Between Builder And Homeowner

Construction Agreement And Sale Agreement

Agreement Between Builder And Owner

Contract Between Contractor And Owner

Standard Contractor Contract

House Building Contract Agreement

Residential Cost Plus Contract

Construction Company Partnership Agreement

Builder And Land Owner Agreement

Standard General Contractor Agreement

Standard Building Contract

Construction Equipment Rental Contract

Contractor Contingency Agreement

Construction Completion Agreement

Construction Agreement Between Client And Contractor

Builder Purchase Agreement

Agreement For Construction Of House With Material

Home Improvement Construction Contract

Pre Construction Purchase Agreement

New Construction Purchase Agreement

Construction Finders Fee Agreement

Collaboration Agreement For Construction Of Building

Simple Residential Construction Contract

Fence Construction Agreement

Construction Disbursement Agreement

Landscape Contractor Contract

Construction Owner's Representative Contract

Owner Subcontractor Agreement

Contract Between Builder And Client

Construction Non Compete Agreement

Building Construction Contract Agreement

Swimming Pool Construction Agreement

Simple Construction Loan Agreement

Owner Builder Subcontractor Agreement

Management Building Contract

Commercial Construction Agreement

Owner Builder Agreement

Construction Referral Fee Agreement

Construction Labor Agreement

Builder Development Agreement

Home Builder Contract

Builder Agreement

Construction Agreement Between Owner And Contractor

Construction Payment Contract

Construction Lease Agreement

New Construction Home Contract

Contract For Contractor And Homeowner

Construction Deposit Agreement

Basic Building Contract

Construction Work Order Agreement

Road Construction Agreement

Construction Employee Contract

Construction Subcontract

General Contractor Agreement With Owner

General Construction Agreement

Pre Construction Agreement

Construction Agency Agreement

Subcontractor Agreement (Construction)

Standard Construction Contract

General Contractor Contract

Construction Contract Agreement

Building Contract Agreement

tiktok��˰�

How a Sales & Marketing Lead uses tiktok��˰� to reduce contract drafting time by 95%

�ұ�Ծ��’s Security Promise