1. Parties: Identifies and provides full details of the property owner and the contractor, including business registration numbers and licenses
2. Background: Brief context about the property, the owner's intention to remodel, and the contractor's expertise and qualifications
3. Definitions: Defines key terms used throughout the agreement including 'Works', 'Property', 'Completion Date', 'Contract Sum', and technical terms
4. Scope of Works: Detailed description of the remodeling work to be performed, including specific areas of the property and types of modifications
5. Contract Sum and Payment Terms: Specifies the total contract value, payment schedule, deposit requirements, and method of payment
6. Timeline and Completion: Sets out the project schedule, start date, completion date, and mechanisms for managing delays
7. Contractor's Obligations: Lists the contractor's responsibilities including quality standards, compliance with regulations, and project management duties
8. Property Owner's Obligations: Specifies the owner's responsibilities including access to the property, timely decisions, and necessary approvals
9. Materials and Equipment: Details regarding the procurement, quality, and approval of materials and equipment
10. Variations and Changes: Process for requesting, approving, and implementing changes to the scope of work
11. Insurance and Liability: Insurance requirements, liability allocation, and indemnification provisions
12. Warranties and Defects: Warranty periods, defects liability period, and rectification procedures
13. Termination: Grounds for termination, notice requirements, and consequences of termination
14. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration provisions
15. General Provisions: Standard legal provisions including notices, governing law, and entire agreement clause
