Standard Renovation Contract

Standard Renovation Contract Template for India

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Standard Renovation Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Standard Renovation Contract for renovating my three-bedroom apartment in Mumbai, with work starting March 2025 and strict noise restriction requirements since it's in a residential complex."

Document background

The Standard Renovation Contract serves as a crucial legal instrument for managing renovation projects in India, whether residential or commercial. This document is specifically designed to comply with Indian contract law, construction regulations, and local building codes. It should be used whenever a property owner engages a contractor for substantial renovation works, providing comprehensive coverage of project scope, timelines, costs, quality standards, and risk allocation. The contract includes essential provisions for permits, warranties, insurance, and dispute resolution, while remaining flexible enough to accommodate project-specific requirements. It addresses key concerns such as material specifications, payment schedules, and work quality standards, making it suitable for both simple and complex renovation projects.

Suggested Sections

1. Parties: Identification and details of the contractor and property owner/client

2. Background: Context of the renovation project and basic premises of the agreement

3. Definitions: Key terms used throughout the contract and their specific meanings

4. Scope of Work: Detailed description of renovation services to be performed

5. Contract Price and Payment Terms: Total cost, payment schedule, and payment methods

6. Timeline and Completion: Project start date, completion date, and key milestones

7. Materials and Workmanship: Quality standards, material specifications, and workmanship warranties

8. Contractor's Obligations: Responsibilities including permits, safety, site management, and cleanup

9. Client's Obligations: Access provisions, approvals, and other client responsibilities

10. Changes and Variations: Process for requesting and implementing changes to scope of work

11. Insurance and Indemnity: Required insurance coverage and indemnification provisions

12. Defects and Warranties: Warranty period, defect resolution process, and quality guarantees

13. Termination: Conditions and process for contract termination by either party

14. Dispute Resolution: Process for resolving disputes including mediation and arbitration

15. General Provisions: Standard contract clauses including notices, governing law, and force majeure

Optional Sections

1. Subcontractors: Terms governing the use and management of subcontractors, used when subcontracting is anticipated

2. Intellectual Property: Protection of designs and creative elements, included when custom designs are part of the renovation

3. Environmental Compliance: Specific environmental protection measures, included for projects with significant environmental impact

4. Temporary Facilities: Provisions for temporary structures or facilities, needed for larger renovation projects

5. Storage and Security: Requirements for material storage and site security, important for longer projects

6. Occupancy During Renovation: Special provisions if property remains occupied during renovation

7. Utilities: Responsibility for utility costs and connections during renovation

8. Permits and Approvals: Detailed section on required permits, used when complex approvals are needed

Suggested Schedules

1. Schedule A - Detailed Scope of Work: Comprehensive breakdown of all renovation works to be performed

2. Schedule B - Price Breakdown: Detailed cost breakdown including materials, labor, and other expenses

3. Schedule C - Project Timeline: Detailed project schedule with milestones and completion dates

4. Schedule D - Material Specifications: Detailed specifications of all materials to be used

5. Schedule E - Drawings and Plans: Technical drawings, design plans, and layouts

6. Schedule F - Safety Protocol: Safety procedures and requirements for the renovation work

7. Appendix 1 - Required Permits: Copies of all necessary permits and approvals

8. Appendix 2 - Insurance Certificates: Copies of required insurance policies

9. Appendix 3 - Payment Schedule: Detailed payment milestones and terms

Authors

Alex Denne

Head of Growth (Open Source Law) @ tiktok��˰� | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate

Interior Design

Architecture

Home Improvement

Commercial Property

Residential Property

Retail

Hospitality

Office Space

Relevant Teams

Legal

Procurement

Operations

Facilities Management

Project Management

Real Estate

Construction

Property Management

Contract Administration

Quality Assurance

Relevant Roles

Property Manager

Facility Manager

Construction Manager

Project Manager

Procurement Manager

Legal Counsel

Contract Administrator

Real Estate Manager

Operations Manager

Renovation Contractor

Interior Designer

Architect

Quality Control Manager

Site Supervisor

Cost Estimator

Find the exact document you need

Lien Contract

An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.

tiktok���˰�

How tiktok���˰� reduced drafting time by 75% for a legal firm

Let's create your Standard Renovation Contract

Authors

Alex Denne

Find the exact document you need

Lien Contract

Labour Contract Form

House Wiring Contract

Handyman Maintenance Contract

General Contract

Contractor Non Compete Agreement

Contractor Lien Release

Contract With Builder

Contractors Agreement Form

Conditions Of Contract For (Construction)

Construction Agreement Contract

Basic Independent Contractor Agreement

Architect Contract Agreement

Simple Contract Labor Agreement

Private Security Contract

Payment Contract Agreement

Building Construction Labour Contract Agreement

Developer Contractor Agreement

Standard Form Of Agreement Between Owner And Contractor

Turnkey Contract

Time And Materials Contract

Standard Renovation Contract

Swimming Pool Contract

Suppliers Contract Agreement

Service Contract Proposal

Residential Solar Installation Contract

Restoration Contract

Receipt Contract

Real Estate Contractor Agreement

Proposal And Contract

Owner's Representative Contract

Masonry Contract

Marketing Agreement Contract

Lump Sum Contract

Insurance Agency Agreement

Labour Only Subcontractor Agreement

Kitchen Renovation Contract

Kitchen Contract

Labour Supply Contract

Joint Contract

Home Improvement Contract

Flooring Contract

Fixed Price Building Contract

Employment Contract For Security Guard

Excavation Contract

Cost Plus Fixed Fee Contract

Cost Plus Contract

Construction Bid Form

Contractor Form

Carpentry Contract

Bid Contract

Bathroom Renovation Contract

Basic Agreement Contract

Agreement Between Owner And Electrical Contractor

Social Media Contract

Medical Independent Contractor Agreement

Demolition Contract

Service Of Work Contract

Generic Work Contract

Landscape Contract

Membership Contract

Standard Form Contract

Purchase And Sale Agreement Contract

Generic Contractor Agreement

Agreement Between Owner And Labour Contractor

Professional Services Subcontractor Agreement

Massage Contractor Agreement

Short Form Contractor Agreement

Home Painting Contract

Cleaning Contractor Agreement

Home Improvement Agreement

House Renovation Contract

Contractor Confidentiality Agreement

Supply Contract

tiktok��˰�

How tiktok��˰� reduced drafting time by 75% for a legal firm

�ұ�Ծ��’s Security Promise